Terms and Conditions

Supreme Tulare Sunrooms & Patios provides residential sunroom construction and outdoor living services in Tulare, CA and surrounding areas in the San Joaquin Valley. Our services include, but are not limited to, sunroom additions, four-season sunrooms, three-season sunrooms, patio enclosures, screen room installation, patio covers, and related design and remodeling work.

We serve residential homeowners and properties located within our defined service area. We reserve the right to decline any project request at our discretion.

Any estimate or quote provided by Supreme Tulare Sunrooms & Patios - whether by phone, email, or in-person - is not a binding contract. Estimates are based on the information available at the time of the site visit and are subject to change if site conditions, scope of work, or material costs change.

A binding agreement is established only when both parties have signed a written contract that specifies the scope of work, materials, timeline, and total price. Do not consider any verbal quote or written estimate to be a contract until a formal agreement is signed.

Prices are subject to change based on material availability, permit requirements, or unforeseen site conditions discovered during construction. Any such changes will be communicated to the customer before additional work is performed, and a written change order will be required before the work proceeds.

Project scheduling is confirmed upon signing of a written contract and receipt of any required deposit. Start dates are estimates and may shift due to permit review timelines, material lead times, weather, or other factors outside our control.

If a customer cancels a signed contract before construction begins, any deposit paid may be forfeited in whole or in part to cover costs already incurred, including materials ordered, permit application fees, and design work. The specific cancellation terms will be detailed in your signed contract.

We reserve the right to reschedule or delay a project start date due to circumstances beyond our control, including permit delays, supply chain issues, or weather conditions. We will notify the customer promptly if a delay is expected.

Payment terms are outlined in the signed written contract for each project. In general, projects require a deposit at contract signing, one or more progress payments tied to project milestones, and a final payment upon project completion and customer acceptance.

Final payment is due upon substantial completion of the project. Failure to make payments on time may result in a work stoppage and may incur additional fees as specified in the contract. All invoices are due upon receipt unless otherwise agreed in writing.

We accept payment by check, bank transfer, or other methods specified in your contract. Do not send cash payments.

For any project that requires a building permit under California law or local ordinance, Supreme Tulare Sunrooms & Patios will apply for the permit on the customer's behalf as part of our standard process. The customer is responsible for ensuring that any applicable homeowners association (HOA) approvals are obtained prior to the start of work, unless we have agreed in writing to handle that process.

Construction will not begin until all required permits are approved. Permit application fees are the customer's responsibility and are included in the project estimate.

Any workmanship warranty offered by Supreme Tulare Sunrooms & Patios will be stated specifically in your written contract. Unless stated otherwise in writing, no warranty is implied. Manufacturer warranties on materials and products pass through to the customer and are subject to the terms set by the respective manufacturer.

We do not warrant against conditions caused by events outside our control, including natural disasters, flooding, earthquake damage, soil movement, or damage caused by others after project completion. Warranty claims must be submitted in writing to hi@tularesunroomcontractor.com.

The information on this website is provided for general informational purposes only. We make no warranties about the accuracy, completeness, or suitability of any content on the site for any particular purpose.

To the maximum extent permitted by applicable law, Supreme Tulare Sunrooms & Patios shall not be liable for any indirect, incidental, consequential, or punitive damages arising from your use of our website or services - including loss of use, loss of revenue, or property damage not directly caused by our negligence.

Our total liability to any customer for claims arising from a specific project shall not exceed the amount paid by that customer for the specific project giving rise to the claim. Some jurisdictions do not allow limitations on implied warranties or liability for consequential damages, so some of these limitations may not apply to you.

If a dispute arises between you and Supreme Tulare Sunrooms & Patios related to our services or these terms, we encourage you to contact us first to try to resolve it informally. Reach out at hi@tularesunroomcontractor.com or (559) 837-6841. Most issues can be resolved quickly with a direct conversation.

If informal resolution is not possible, disputes shall be submitted to binding arbitration in Tulare, CA, under the rules of the American Arbitration Association. The parties waive any right to a jury trial. Nothing in this clause prevents either party from seeking injunctive relief in a court of competent jurisdiction where necessary to prevent irreparable harm.

You may use this website for lawful purposes only. You may not use it in any way that violates applicable local, state, national, or international law or regulation. You agree not to attempt to gain unauthorized access to any part of the site or its related systems or networks.

All content on this site - including text, images, and design - is the property of Supreme Tulare Sunrooms & Patios or its content providers and is protected by applicable copyright and trademark law. You may not reproduce, distribute, or use site content for commercial purposes without our written permission.

For questions about these terms, contact us at:

Supreme Tulare Sunrooms & Patios

143 S H St

Tulare, CA 93274

hi@tularesunroomcontractor.com

(559) 837-6841